Terms of use

Agreement to Terms

Welcome to Taqdeer Builders. These terms of use ("Terms") govern your use of our website taqdeerbuilders.com and our construction services.

By accessing our website or using our services, you agree to be bound by these Terms. If you do not agree with any part of these terms, please do not use our website or services.

Our Services

Taqdeer Builders provides house construction services in Kharar, Mohali, Chandigarh, Zirakpur, Derabassi. The services described on this website are:

• Turnkey construction on your plot
• Plot assistance
• NRI construction coordination

Ready-to-move homes are planned; none are on offer yet.

Website Use

Permitted Use

You may use our website for lawful purposes only. You agree to:

• Provide accurate information when contacting us
• Use the website in compliance with applicable laws
• Not interfere with the website's operation
• Not attempt to gain unauthorized access to our systems

Prohibited Activities

You agree not to:

• Use the website for any illegal purpose
• Transmit harmful code, viruses, or malware
• Attempt to breach our security measures
• Copy, reproduce, or distribute our content without permission
• Use automated systems to access the website
• Impersonate others or provide false information

Construction Service Terms

Quotations & Estimates

All quotations and cost estimates provided on our website or during consultations are indicative and subject to:

• Site inspection and verification
• Final design and specifications
• Current material prices
• Applicable taxes and government charges

Final pricing will be confirmed in a written agreement before project commencement.

Project Agreements

All construction projects require a separate written agreement that will include:

• Detailed scope of work
• Project timeline and milestones
• Payment schedule and terms
• Material specifications
• Warranty terms, if any
• Terms and conditions specific to the project

Payment Terms

Payment terms for construction projects will be specified in the project agreement. Generally, payments are made in stages based on project milestones. Delayed payments may result in project delays.

Intellectual Property

Text and logo are owned by Taqdeer Builders; some photographs are licensed stock images and remain the property of their owners. Please ask before reusing any content from this website.

Calculator Tools & Information

Our website provides construction cost calculators and informational tools. Estimates from the site's tools are indicative, not quotations. Please note:

• Calculator results are estimates only and not final quotes
• Actual costs may vary based on site conditions, design, and materials
• Information is for general guidance and may not reflect current prices
• Always consult with us for accurate project quotations

Disclaimer

While we strive to provide accurate information:

• Website content is provided "as is" without warranties
• We do not guarantee uninterrupted or error-free website access
• Information may be outdated and is subject to change
• We are not liable for decisions made based on website content

For accurate and up-to-date information, please contact us directly.

Limitation of Liability

To the maximum extent permitted by law, Taqdeer Builders shall not be liable for:

• Any indirect, incidental, or consequential damages
• Loss of profits, data, or business opportunities
• Damages arising from website use or inability to use
• Third-party actions or content

Our total liability for any claim shall not exceed the amount paid by you for our services.

Third-Party Links

Our website may contain links to third-party websites and services (e.g., WhatsApp, Instagram, Google Maps). We are not responsible for the content, privacy policies, or practices of these external sites. Use of third-party services is at your own risk.

Indemnification

You agree to indemnify and hold harmless Taqdeer Builders, its owners, employees, and partners from any claims, damages, losses, or expenses arising from your violation of these Terms or your use of our website and services.

Governing Law

These Terms shall be governed by and construed in accordance with the laws of India. Any disputes arising from these Terms or your use of our services shall be subject to the exclusive jurisdiction of the courts in Mohali, Punjab, India.

For construction projects, specific dispute resolution mechanisms may be outlined in individual project agreements.

Changes to Terms

We reserve the right to modify these Terms at any time. Changes will be effective immediately upon posting on this page. Your continued use of our website after changes constitutes acceptance of the revised Terms. We encourage you to review these Terms periodically.

Severability

If any provision of these Terms is found to be unenforceable or invalid, that provision shall be limited or eliminated to the minimum extent necessary, and the remaining provisions shall remain in full force and effect.